Welcome to S2 Logic System. By accessing or using our website (s2logicsystem.com) and our services, you agree to comply with and be bound by the following terms and conditions. If you do not agree with any part of these terms, please do not use our services.
1. Acceptance of Terms
By engaging with S2 Logic System for web development, app development, or digital marketing services, you acknowledge that you have read, understood, and agreed to these Terms of Use.
2. Services Provided
S2 Logic System provides various digital services, including but not limited to:
Custom Web & Mobile App Development
UI/UX Design
Digital Marketing & SEO
Software Maintenance & Bug Fixing
3. Intellectual Property Rights
Unless otherwise stated, S2 Logic System and/or its licensors own the intellectual property rights for all material on this website. All intellectual property rights are reserved. You may access this from S2 Logic System for your own personal use subjected to restrictions set in these terms. Note: Upon full payment for a project, the ownership of the final source code and assets will be transferred to the client, unless specified otherwise in the contract.
4. User Obligations
As a user of this website, you agree:
To provide accurate and current information.
Not to use the website for any unlawful purpose.
Not to attempt to interfere with the website’s security or performance.
5. Payment Terms
Projects are initiated after an initial deposit/advance payment.
Remaining payments must be made according to the milestones agreed upon in the project proposal.
Delay in payments may result in a temporary suspension of work.
6. Limitation of Liability
S2 Logic System will not be held liable for any indirect, consequential, or special liability arising out of or in any way related to your use of this website or our services. We strive for excellence, but we do not guarantee that our services will be 100% error-free or uninterrupted.
7. Termination
We reserve the right to terminate or suspend access to our services immediately, without prior notice or liability, for any reason, including if you breach the Terms.
8. Governing Law
These terms are governed by and construed in accordance with the laws of Uttar Pradesh, India, and you irrevocably submit to the exclusive jurisdiction of the courts in that location.
9. Contact Information
If you have any questions about these Terms, please contact us:
Email: s2logicsystems@gmail.com
Address: Sector 62A, Noida, Uttar Pradesh 201020